P400--Building 149 and 150 Demolition 552-26-201

Description

{"description":"STATEMENT OF WORK (SOW)\n\nContract Title. 552-26-203 Demolition of Buildings 149 and 150\nBackground. \nThis Statement of Work (SOW) outlines the requirements for demolishing two brick buildings, designated as Building 149 and Building 150. Both buildings have experienced a complete roof collapse causing substantial damage to the supporting walls. The extent of the damage renders the buildings irreparable, necessitating complete demolition of roof structure, and exterior supporting walls. Building 149 is located in a large courtyard surrounded by other structures and connecting corridors, which necessitates additional access and demolition considerations.\nScope. The contractor shall supply all necessary labor, materials, equipment, and services to execute the following tasks: \n\nDemolition. Demolition of Building walls and roof system in their entirety.\n\nUtility Removal and Termination.\nRemoval and safe termination of steam and condensate return lines in each building at their source.\nRemoval and safe termination of electrical systems in each building at their source.\nRemoval and safe termination of water supply in each building at their source.\nThe contractor shall provide a detailed Utility Shutdown Plan outlining the steps and precautions for safely shutting down, de-energizing, and terminating all utilities for these two buildings.\n\nRetention of Structural Elements.\nThe concrete floor of each building is to be protected and preserved.\nSidewalks adjacent to both buildings are to be protected and preserved.\nTunnels with concrete lids are to be protected and preserved.\n\n Temporary Fencing.\nInstallation and maintenance of temporary fencing around the entire perimeter of the demolition sites for both Building 149 and Building 150 for the duration of the project .\nFencing must be a minimum of six (6) feet high and secured to prevent unauthorized access.\nClearly marked construction site signs to be placed on the fencing to indicate restricted access and necessary safety precautions.\n\n Construction Waste Documentation.\nThe contractor shall document all construction waste generated during the demolition process.\nProvide documentation to the COR detailing the types and quantities of construction waste, including disposal methods and locations.\n\n Daily Logs.\nThe contractor shall maintain and submit daily logs of all activities on the site.\nDaily Logs should include details of work performed, personnel on-site, equipment used, any safety incidents or near misses, and any other relevant information.\nDaily logs should be submitted to the Contracting Officer's Representative by the end of each work week.\n\nPerformance Monitoring. The Contracting Officer or their Representative will perform inspections to verify compliance with the SOW.\nSecurity Requirements. The C&A requirements do not apply, and a Security Accreditation Package is not required.\nSecurity Badges. \nAll contractor personnel must be issued and visibly wear security badges at all times while on-site.\nSecurity badges must include the contractor's name and photo identification.\nProcedures for obtaining and returning security badges must be coordinated with the Contracting Officer's Representative.\n\nSafety and Compliance.\nDemolition activities must strictly comply with all applicable federal, state, and local regulations, ensuring adherence to the highest safety and environmental standards. This includes, but is not limited to:\n\nOccupational Safety and Health Administration (OSHA) Standards.\nOSHA 29 CFR 1926 Subpart T - Demolition, which outlines general safety and health provisions specific to demolition activities.\nOSHA 29 CFR 1910.147 - The control of hazardous energy (lockout/tagout) to prevent accidental startup of machinery and the release of hazardous energy.\nOSHA 29 CFR 1926 Subpart E - Personal Protective and Life Saving Equipment, ensuring all workers are equipped with the necessary safety gear.\n\nEnvironmental Protection Agency (EPA) Regulations.\nCompliance with the Clean Water Act (CWA) for managing water runoff and discharges.\nAdherence to the Clean Air Act (CAA) for controlling dust and emissions, particularly the National Emission Standards for Hazardous Air Pollutants (NESHAP) regarding asbestos.\n\nMaster Specification.\nSpecification 02 41 00 Demolition\nSpecification 01 35 26 Safety Requirements for Major Projects\n\nState and Local Regulations.\nObtain all necessary permits from state and local authorities, including demolition permits and waste disposal permits.\nAdherence to state-specific occupational safety regulations and environmental protection guidelines.\n\nNational Fire Protection Association (NFPA) Standards.\nNFPA 70 (National Electrical Code) for ensuring all electrical disconnections are performed safely.\nNFPA 241 for safeguarding construction, alteration, and demolition operations.\n\nHazardous Material Handling.\nCompliance with the Resource Conservation and Recovery Act (RCRA) for the management and disposal of hazardous waste.\nAdherence to Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA) for any potential hazardous substance releases and required reporting.\nAll activities must be conducted under the supervision of qualified and certified personnel, ensuring complete adherence to these standards and regulations. Detailed records of compliance shall be maintained and available for review upon request.\nThe contractor shall implement a site-specific safety plan addressing all potential hazards, including the safe removal of materials of unknown type and quantity buried under the roof debris. \n\nUtility Termination.\nThe contractor shall verify, ensure, and coordinate the proper disconnection and termination of all utility lines, including steam, water, and electricity associated with these two buildings. This involves collaborating with relevant utility providers, conducting thorough inspections to confirm disconnections, and implementing safety protocols to prevent any accidental utility service disruptions or hazards during the demolition process.\nThe contractor shall obtain all necessary permits and approvals required for the termination of utility services. This includes coordinating activities with Engineering and effected services, submitting detailed shop drawings and documentation, and ensuring compliance with all relevant regulations and codes for the safe disconnection of utilities such as water, electricity, and steam lines.\nThe contractor is strictly prohibited from performing any electrical hot work under any circumstances. Prior to commencing any demolition or construction activities, all electrical systems must be completely de-energized. This process includes isolating and shutting down power sources, locking out and tagging out all electrical circuits in accordance with OSHA Standard 29 CFR 1910.147 for the control of hazardous energy, and thoroughly verifying that the area is safe to work in through proper testing and inspection procedures as outlined in NFPA 70E. Additionally, the contractor must maintain documentation confirming that these safety measures have been implemented and adhered to, including compliance with the National Electrical Code (NEC) and other relevant federal, state, and local regulations.\nThe contractor is required to provide a comprehensive Utility Shutdown Plan that outlines the specific steps and precautions for safely shutting down, de-energizing, and terminating all utility services. This plan must adhere to all relevant regulations and standards, including but not limited to OSHA Standard 29 CFR 1910.147, which covers the control of hazardous energy (lockout/tagout) procedures, and NFPA 70E for electrical safety in the workplace.\n \nThe plan should include:\nIdentification and assessment of all utility lines, including electricity, water, steam, gas, and any other services.\nDetailed procedures for isolating and shutting down power sources in compliance with OSHA lockout/tagout requirements.\nVerification processes to ensure complete de-energization and safety, involving appropriate testing and inspection protocols as per NFPA 70E.\nCoordination with utility providers and relevant regulatory agencies to secure all necessary permits and approvals for utility termination, ensuring compliance with federal, state, and local codes, including the National Electrical Code (NEC).\nSafety precautions to protect workers and the environment from potential hazards associated with the utility shutdown.\nDocumentation and records of all steps taken in the shutdown process, including signed verification of de-energization and termination by qualified personnel.\nThis Utility Shutdown Plan must be submitted for approval prior to the commencement of any demolition or construction activities.\n\nSite Protection.\nEnsure protection of the concrete floor, sidewalks, and tunnels throughout the demolition process.\nAny damage to the retained structures must be repaired at the contractor's expense.\nAdditional Considerations for Building 149.\nGiven the building's location in a large courtyard surrounded by other structures and enclosed connecting corridors, it is essential to undertake additional planning and precautions to ensure the safety and integrity of the adjacent buildings and structures.\nThe contractor must develop and submit a comprehensive access plan to ensure safe entry and exit from the courtyard, while minimizing disruption to the adjacent buildings.\nCoordinate with the Contracting Officer s Representative (COR) for stakeholders or departments occupying the surrounding buildings to address any potential concerns and establish a schedule that minimizes disruption to ongoing operations.\nPerform structural assessments and institute monitoring of adjacent buildings and connecting corridors to prevent any damage during demolition activities.\nImplement dust control and noise mitigation measures to minimize disturbances to the occupants of the surrounding buildings.\nMaterials of unknown type and quantity have been identified to be in and beneath the collapsed roof structure and will need to be safely removed, preventing spills or runoff, and disposed of accordingly. Please refer to the attached photographs of Building 149. \nProvide a detailed description of all hazardous materials located in the structure and provide it to the Contracting Officer Representative (COR).\n\nAdditional Considerations for Building 150.\nThe contractor must develop and submit a comprehensive access plan to ensure safe entry and exit from the courtyard, while minimizing disruption to the adjacent buildings.\nCoordinate with the Contracting Officer s Representative (COR) for stakeholders or departments occupying the surrounding buildings to address any potential concerns and establish a schedule that minimizes disruption to ongoing operations.\nPerform structural assessments and institute monitoring of adjacent buildings.\nImplement dust control and noise mitigation measures to minimize disturbances to the occupants of the surrounding buildings.\nMaterials of unknown type and quantity have been identified to be in and beneath the collapsed roof structure and will need to be safely removed, preventing spills or runoff, and disposed of accordingly. Please refer to the attached photographs of Building150.\nProvide a detailed description of all hazardous materials located in the structure and provide it to the Contracting Officer Representative (COR).\n\nDeliverables.\nA detailed project schedule, including milestones, to be submitted within 10 days of NTP.\nWeekly progress reports detailing complete work, safety compliance, and any issues encountered.\nFinal report upon completion, including photographs of the retained structural elements.\nUtility Shutdown Plan for the safe shutdown, de-energizing, and termination of all utilities.\nConstruction waste documentation detailing the types and quantities of construction waste, including disposal methods and locations.\nDaily logs of all on-site activities, submitted to the Contracting Officer's Representative by the end of each working week.\nSecurity Badging documentation. \n\nSubmittal Requirements.\nRisk Assessment Safety Plan.\nEnvironmental Protection Plan.\nDetailed Abatement Plan.\nPermits and Approvals for Utility Termination.\nDetailed Demolition Plan, Including Methods for Protecting Retained Structures.\nHazardous Materials Survey and Inventory.\nAccess Plan for Building 149.\nCoordination Plan for Surrounding Buildings.\nUtility Shutdown Plan.\nConstruction waste documentation.\nDaily logs of on-site activities.\n \nQuality Control.\nThe contractor shall implement a Quality Control Plan to ensure compliance with the Statement of Work (SOW) requirements and verify that all work is performed to the specified standards and specifications.\n\nInspection and Acceptance Criteria. Final acceptance will be based on:\nSuccessful demolition and removal of specified elements.\nSafe disconnection and termination of utilities.\nPreservation of specified structural elements without damage.\nSuccessful implementation of access and coordination plans for Building 149.\nProper installation and maintenance of temporary fencing throughout the project duration.\nSuccessful execution of the Utility Shutdown Plan.\nSubmission of complete and accurate construction waste documentation.\nConsistent and timely submission of daily logs.\n\nPlace of Performance. 4100 West Third St., B149 and B150, Dayton, Ohio 45428\n\nPeriod of Performance. The contractor shall complete all tasks within 120 days from the issuance date of the Notice to Proceed (NTP)\n\nSpecifications.\n01 00 00 - General Requirements\n01 32 16.15 - Project Schedules (Small Projects)\n01 33 23 - Shop Drawings, Product Data, and Samples\n01 35 26 - Safety Requirements\n01 45 00 - Quality Control\n01 45 29 - Testing Laboratory Services\n01 57 19 - Temporary Environmental Controls\n01 74 19 - Construction Waste Management\n02 41 00 Demolition\n02 82 11 - Traditional Asbestos Abatement\n02 82 13.41 - Asbestos Abatement for Total Demolition Project\n02 83 33.13 - Lead-Based Paint Removal and Disposal\n26 24 16 - Panelboards\n26 29 21 - Enclosed Switches and Circuit Breakers\n33 63 00 - Steam Energy Distribution\n"} Solicitation Number: 36C25026B0027 Type: Solicitation Base Type: Presolicitation NAICS: 238910 Classification Code: P400 Response Deadline: 2026-03-13T10:00:00-04:00 Office Address: DAYTON, OH POC: Julie A Stout, Julie.Stout@va.gov {"description":"STATEMENT OF WORK (SOW)\n\nContract Title. 552-26-203 Demolition of Buildings 149 and 150\nBackground. \nThis Statement of Work (SOW) outlines the requirements for demolishing two brick buildings, designated as Building 149 and Building 150. Both buildings have experienced a complete roof collapse causing substantial damage to the supporting walls. The extent of the damage renders the buildings irreparable, necessitating complete demolition of roof structure, and exterior supporting walls. Building 149 is located in a large courtyard surrounded by other structures and connecting corridors, which necessitates additional access and demolition considerations.\nScope. The contractor shall supply all necessary labor, materials, equipment, and services to execute the following tasks: \n\nDemolition. Demolition of Building walls and roof system in their entirety.\n\nUtility Removal and Termination.\nRemoval and safe termination of steam and condensate return lines in each building at their source.\nRemoval and safe termination of electrical systems in each building at their source.\nRemoval and safe termination of water supply in each building at their source.\nThe contractor shall provide a detailed Utility Shutdown Plan outlining the steps and precautions for safely shutting down, de-energizing, and terminating all utilities for these two buildings.\n\nRetention of Structural Elements.\nThe concrete floor of each building is to be protected and preserved.\nSidewalks adjacent to both buildings are to be protected and preserved.\nTunnels with concrete lids are to be protected and preserved.\n\n Temporary Fencing.\nInstallation and maintenance of temporary fencing around the entire perimeter of the demolition sites for both Building 149 and Building 150 for the duration of the project .\nFencing must be a minimum of six (6) feet high and secured to prevent unauthorized access.\nClearly marked construction site signs to be placed on the fencing to indicate restricted access and necessary safety precautions.\n\n Construction Waste Documentation.\nThe contractor shall document all construction waste generated during the demolition process.\nProvide documentation to the COR detailing the types and quantities of construction waste, including disposal methods and locations.\n\n Daily Logs.\nThe contractor shall maintain and submit daily logs of all activities on the site.\nDaily Logs should include details of work performed, personnel on-site, equipment used, any safety incidents or near misses, and any other relevant information.\nDaily logs should be submitted to the Contracting Officer's Representative by the end of each work week.\n\nPerformance Monitoring. The Contracting Officer or their Representative will perform inspections to verify compliance with the SOW.\nSecurity Requirements. The C&A requirements do not apply, and a Security Accreditation Package is not required.\nSecurity Badges. \nAll contractor personnel must be issued and visibly wear security badges at all times while on-site.\nSecurity badges must include the contractor's name and photo identification.\nProcedures for obtaining and returning security badges must be coordinated with the Contracting Officer's Representative.\n\nSafety and Compliance.\nDemolition activities must strictly comply with all applicable federal, state, and local regulations, ensuring adherence to the highest safety and environmental standards. This includes, but is not limited to:\n\nOccupational Safety and Health Administration (OSHA) Standards.\nOSHA 29 CFR 1926 Subpart T - Demolition, which outlines general safety and health provisions specific to demolition activities.\nOSHA 29 CFR 1910.147 - The control of hazardous energy (lockout/tagout) to prevent accidental startup of machinery and the release of hazardous energy.\nOSHA 29 CFR 1926 Subpart E - Personal Protective and Life Saving Equipment, ensuring all workers are equipped with the necessary safety gear.\n\nEnvironmental Protection Agency (EPA) Regulations.\nCompliance with the Clean Water Act (CWA) for managing water runoff and discharges.\nAdherence to the Clean Air Act (CAA) for controlling dust and emissions, particularly the National Emission Standards for Hazardous Air Pollutants (NESHAP) regarding asbestos.\n\nMaster Specification.\nSpecification 02 41 00 Demolition\nSpecification 01 35 26 Safety Requirements for Major Projects\n\nState and Local Regulations.\nObtain all necessary permits from state and local authorities, including demolition permits and waste disposal permits.\nAdherence to state-specific occupational safety regulations and environmental protection guidelines.\n\nNational Fire Protection Association (NFPA) Standards.\nNFPA 70 (National Electrical Code) for ensuring all electrical disconnections are performed safely.\nNFPA 241 for safeguarding construction, alteration, and demolition operations.\n\nHazardous Material Handling.\nCompliance with the Resource Conservation and Recovery Act (RCRA) for the management and disposal of hazardous waste.\nAdherence to Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA) for any potential hazardous substance releases and required reporting.\nAll activities must be conducted under the supervision of qualified and certified personnel, ensuring complete adherence to these standards and regulations. Detailed records of compliance shall be maintained and available for review upon request.\nThe contractor shall implement a site-specific safety plan addressing all potential hazards, including the safe removal of materials of unknown type and quantity buried under the roof debris. \n\nUtility Termination.\nThe contractor shall verify, ensure, and coordinate the proper disconnection and termination of all utility lines, including steam, water, and electricity associated with these two buildings. This involves collaborating with relevant utility providers, conducting thorough inspections to confirm disconnections, and implementing safety protocols to prevent any accidental utility service disruptions or hazards during the demolition process.\nThe contractor shall obtain all necessary permits and approvals required for the termination of utility services. This includes coordinating activities with Engineering and effected services, submitting detailed shop drawings and documentation, and ensuring compliance with all relevant regulations and codes for the safe disconnection of utilities such as water, electricity, and steam lines.\nThe contractor is strictly prohibited from performing any electrical hot work under any circumstances. Prior to commencing any demolition or construction activities, all electrical systems must be completely de-energized. This process includes isolating and shutting down power sources, locking out and tagging out all electrical circuits in accordance with OSHA Standard 29 CFR 1910.147 for the control of hazardous energy, and thoroughly verifying that the area is safe to work in through proper testing and inspection procedures as outlined in NFPA 70E. Additionally, the contractor must maintain documentation confirming that these safety measures have been implemented and adhered to, including compliance with the National Electrical Code (NEC) and other relevant federal, state, and local regulations.\nThe contractor is required to provide a comprehensive Utility Shutdown Plan that outlines the specific steps and precautions for safely shutting down, de-energizing, and terminating all utility services. This plan must adhere to all relevant regulations and standards, including but not limited to OSHA Standard 29 CFR 1910.147, which covers the control of hazardous energy (lockout/tagout) procedures, and NFPA 70E for electrical safety in the workplace.\n \nThe plan should include:\nIdentification and assessment of all utility lines, including electricity, water, steam, gas, and any other services.\nDetailed procedures for isolating and shutting down power sources in compliance with OSHA lockout/tagout requirements.\nVerification processes to ensure complete de-energization and safety, involving appropriate testing and inspection protocols as per NFPA 70E.\nCoordination with utility providers and relevant regulatory agencies to secure all necessary permits and approvals for utility termination, ensuring compliance with federal, state, and local codes, including the National Electrical Code (NEC).\nSafety precautions to protect workers and the environment from potential hazards associated with the utility shutdown.\nDocumentation and records of all steps taken in the shutdown process, including signed verification of de-energization and termination by qualified personnel.\nThis Utility Shutdown Plan must be submitted for approval prior to the commencement of any demolition or construction activities.\n\nSite Protection.\nEnsure protection of the concrete floor, sidewalks, and tunnels throughout the demolition process.\nAny damage to the retained structures must be repaired at the contractor's expense.\nAdditional Considerations for Building 149.\nGiven the building's location in a large courtyard surrounded by other structures and enclosed connecting corridors, it is essential to undertake additional planning and precautions to ensure the safety and integrity of the adjacent buildings and structures.\nThe contractor must develop and submit a comprehensive access plan to ensure safe entry and exit from the courtyard, while minimizing disruption to the adjacent buildings.\nCoordinate with the Contracting Officer s Representative (COR) for stakeholders or departments occupying the surrounding buildings to address any potential concerns and establish a schedule that minimizes disruption to ongoing operations.\nPerform structural assessments and institute monitoring of adjacent buildings and connecting corridors to prevent any damage during demolition activities.\nImplement dust control and noise mitigation measures to minimize disturbances to the occupants of the surrounding buildings.\nMaterials of unknown type and quantity have been identified to be in and beneath the collapsed roof structure and will need to be safely removed, preventing spills or runoff, and disposed of accordingly. Please refer to the attached photographs of Building 149. \nProvide a detailed description of all hazardous materials located in the structure and provide it to the Contracting Officer Representative (COR).\n\nAdditional Considerations for Building 150.\nThe contractor must develop and submit a comprehensive access plan to ensure safe entry and exit from the courtyard, while minimizing disruption to the adjacent buildings.\nCoordinate with the Contracting Officer s Representative (COR) for stakeholders or departments occupying the surrounding buildings to address any potential concerns and establish a schedule that minimizes disruption to ongoing operations.\nPerform structural assessments and institute monitoring of adjacent buildings.\nImplement dust control and noise mitigation measures to minimize disturbances to the occupants of the surrounding buildings.\nMaterials of unknown type and quantity have been identified to be in and beneath the collapsed roof structure and will need to be safely removed, preventing spills or runoff, and disposed of accordingly. Please refer to the attached photographs of Building150.\nProvide a detailed description of all hazardous materials located in the structure and provide it to the Contracting Officer Representative (COR).\n\nDeliverables.\nA detailed project schedule, including milestones, to be submitted within 10 days of NTP.\nWeekly progress reports detailing complete work, safety compliance, and any issues encountered.\nFinal report upon completion, including photographs of the retained structural elements.\nUtility Shutdown Plan for the safe shutdown, de-energizing, and termination of all utilities.\nConstruction waste documentation detailing the types and quantities of construction waste, including disposal methods and locations.\nDaily logs of all on-site activities, submitted to the Contracting Officer's Representative by the end of each working week.\nSecurity Badging documentation. \n\nSubmittal Requirements.\nRisk Assessment Safety Plan.\nEnvironmental Protection Plan.\nDetailed Abatement Plan.\nPermits and Approvals for Utility Termination.\nDetailed Demolition Plan, Including Methods for Protecting Retained Structures.\nHazardous Materials Survey and Inventory.\nAccess Plan for Building 149.\nCoordination Plan for Surrounding Buildings.\nUtility Shutdown Plan.\nConstruction waste documentation.\nDaily logs of on-site activities.\n \nQuality Control.\nThe contractor shall implement a Quality Control Plan to ensure compliance with the Statement of Work (SOW) requirements and verify that all work is performed to the specified standards and specifications.\n\nInspection and Acceptance Criteria. Final acceptance will be based on:\nSuccessful demolition and removal of specified elements.\nSafe disconnection and termination of utilities.\nPreservation of specified structural elements without damage.\nSuccessful implementation of access and coordination plans for Building 149.\nProper installation and maintenance of temporary fencing throughout the project duration.\nSuccessful execution of the Utility Shutdown Plan.\nSubmission of complete and accurate construction waste documentation.\nConsistent and timely submission of daily logs.\n\nPlace of Performance. 4100 West Third St., B149 and B150, Dayton, Ohio 45428\n\nPeriod of Performance. The contractor shall complete all tasks within 120 days from the issuance date of the Notice to Proceed (NTP)\n\nSpecifications.\n01 00 00 - General Requirements\n01 32 16.15 - Project Schedules (Small Projects)\n01 33 23 - Shop Drawings, Product Data, and Samples\n01 35 26 - Safety Requirements\n01 45 00 - Quality Control\n01 45 29 - Testing Laboratory Services\n01 57 19 - Temporary Environmental Controls\n01 74 19 - Construction Waste Management\n02 41 00 Demolition\n02 82 11 - Traditional Asbestos Abatement\n02 82 13.41 - Asbestos Abatement for Total Demolition Project\n02 83 33.13 - Lead-Based Paint Removal and Disposal\n26 24 16 - Panelboards\n26 29 21 - Enclosed Switches and Circuit Breakers\n33 63 00 - Steam Energy Distribution\n"}